Winona County Minnesota Roofing Expert Witness Directory

Credibility Matters…Even in Delay Claims

September 29, 2026 — David Adelstein - Florida Construction Legal Updates
Credibility matters. Here’s another example involving a delay claim on public private partnership delivery method. The project agreement required claims to be tried by a hearing examiner. The public private partnership developer (for lack of a better term) submitted delay claims that it contended were caused by Miami-Dade County. The hearing examiner awarded the developer delay time and compensation. On appeal, the County argued that the delays awarded by the hearing examiner were concurrent critical path delays with other delays caused by the developer’s team (the developer’s contractor). This was demonstrated by the fact that in an attempt to mitigate the County delay, the contractor’s incorporated a schedule fragnet into its schedule to mitigate delay that showed the critical path was driven by events deemed caused by the contractor. This was also reported in the contractor’s monthly updates. The developer argued that its mitigation plan did not work and, thus, the schedules showed a hypothetical delay caused by the contractor when, in actuality, it was the County-caused delay that drove the critical path. The hearing officer agreed with the contractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Motion for Summary Judgment Granted in Significant California Public Utilities Suit

May 12, 2026 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Congratulations to Partner Mike D’Andrea and Associates Ruth Rasiah and Kaylah Abdullah in the Los Angeles office for obtaining a complete dismissal of their clients in a significant claim involving California’s Public Utilities regulations. After lengthy litigation, BWB&O’s Motion for Summary Judgment was granted against Claimant, Spectrum (Charter Communications), which resulted in a complete dismissal of the action against BWB&O’s clients. At issue was whether California’s Public Utilities Code shifted the common law duty to maintain certain utility equipment in residential areas within Southern California. After significant briefing, the Superior Court found that BWB&O correctly argued that the Public Utilities Code required utility companies, like Spectrum, to fully maintain utility equipment, and that private residents are not responsible for utility maintenance (even if the physical equipment is located on private property). Read the full story...
Reprinted courtesy of Bremer Whyte Brown & O'Meara LLP

GRSM Partner Debra Ellwood Meppen Recognized as 2026 Legal Visionary by Los Angeles Times

June 02, 2026 — Gordon Rees Scully Mansukhani
Gordon Rees Scully Mansukhani proudly congratulates Partner Debra Ellwood Meppen on being named a 2026 Legal Visionary by the Los Angeles Times. The LA Times Studios 2026 Legal Visionaries List recognizes lawyers in Southern California who “exemplify a forward-thinking approach to the law, elevating both their profession and the people who depend on it.” Meppen is recognized for helping shape the future of the legal profession through her leadership, professionalism, and integrity. Published as part of the May 2026 issue highlighting Southern California’s leading law firms and attorneys, the Legal Visionaries section honors attorneys making a significant impact on the legal industry and the broader business community. Read the full story...
Reprinted courtesy of Gordon Rees Scully Mansukhani

Lost in Translation: AEC Tech’s Missing Role

May 12, 2026 — Aarni Heiskanen - AEC Business
I once visited a construction site where the contractor’s headquarters had commissioned a tech company to build an on-site quality-inspection application. The developer had admitted to the site engineer that they had never set foot on a construction site before. The engineer showed me what he was actually using: his own phone camera and an Excel sheet. The new app did not map to how work actually happened on site. This is not an isolated story. The vendor builds something technically coherent but operationally disconnected. The client, somewhere up the chain, had fallen in love with the idea of the solution before anyone had built an honest business case for it. The result is a tool that gets demonstrated at a board meeting but isn’t used in the field. Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Traub Lieberman Attorneys Recognized in the 2027 Edition of The Best Lawyers in America®

September 08, 2026 — Traub Lieberman
Traub Lieberman is pleased to announce that four Partners have been selected by their peers for inclusion in the 2027 edition of The Best Lawyers in America®. In addition, six attorneys have been included in the 2027 Best Lawyers®: Ones to Watch list. These recognitions include attorneys from the firm’s White Plains, NY; Chicago, IL; Palm Beach Gardens, FL; and St. Petersburg, FL offices. 2027 Best Lawyers® White Plains, NY

Lisa L. Shrewsberry – Commercial Litigation

Chicago, IL

Brian C. Bassett – Insurance Law

Palm Beach Gardens, FL

Rina Clemens – Personal Injury Litigation – Defendants, Product Liability Litigation – Defendants

St. Petersburg, FL

Lauren S. Curtis – Insurance Law

Read the full story...
Reprinted courtesy of Traub Lieberman

Global Insights Center: Monthly Newsletter

June 15, 2026 — Global Insights Center Staff - The Hartford
May in Review Last month, inflation moved higher, with Consumer Price Index (CPI) inflation rising to 3.8% year over year, up from 3.3% the prior month. The increase was driven primarily by energy prices, particularly gasoline, reflecting ongoing disruptions tied to the Middle East conflict. Labor market data were broadly stable. The unemployment rate remained unchanged at 4.3%, wage growth increased modestly to 3.6%, while job growth continued to be geographically concentrated in the Southern states, particularly cities in Texas. On an occupational basis, healthcare once again led job gains, especially in home health services, a trend we have consistently highlighted. Business formations increased during the month, with notable strength in e commerce and digital services firms. Manufacturing activity also improved, particularly in semiconductors, IT equipment, and natural gas–related energy infrastructure. Read the full story...
Reprinted courtesy of Global Insights Center Staff, The Hartford

Four HHMR Attorneys Recognized in the 2027 Editions of Best Lawyers®

September 21, 2026 — Higgins, Hopkins, McLain & Roswell, LLC - Colorado Construction Litigation Blog
Higgins, Hopkins, McLain & Roswell, LLC is proud to announce that Best Lawyers® has recognized four HHMR attorneys in the 2027 editions of The Best Lawyers in America® and Best Lawyers: Ones to Watch® in America for their work in construction law and construction litigation. David M. McLain, Lisa Bondy Dunn, and Steven L. Heisdorffer earned recognition in the 2027 edition of The Best Lawyers in America®. Ricky L. Nolen, Jr. earned recognition in the 2027 edition of Best Lawyers: Ones to Watch® in America. For a firm that has deliberately focused its practice on construction law and construction litigation for nearly 25 years, we take particular pride in seeing that focus reflected in the recognition of lawyers across different generations of HHMR. Read the full story...
Reprinted courtesy of Higgins, Hopkins, McLain & Roswell, LLC

Consider The Limited Warranty from Your Homebuilder

July 06, 2026 — David Adelstein - Florida Construction Legal Updates
When purchasing a home from a homebuilder, there is an important consideration when it comes to the limited warranty you receive around the time you close on the home. That limited warranty likely includes an arbitration provision requiring you to arbitrate your disputes, such as construction defect claims, against the homebuilder. That arbitration provision will most likely include all claims, including statutory claims (such as a statutory violation of a building code claim), requiring you to arbitrate, as opposed to litigate, your disputes against the homebuilder. This is an important consideration. If the arbitration provision does not allow you to arbitrate all of your claims, and eliminates your rights to legitimate statutory claims, the arbitration provision could be unenforceable. By way of example, in a residential construction defect dispute, Anderson v. Taylor Morrison of Florida, Inc., 223 So.3d 1088 (Fla. 2d DCA 2017), the appeal turned on whether the arbitration provision in the homebuilder’s limited warranty was valid. The homeowners took possession of their home in 2009. In 2015, the homeowners served a Florida Statutes Chapter 558 notice of construction defects that included a statutory violation of a building code claim under Florida Statute §553.84. The limited warranty included an arbitration provision that specified it was the “exclusive remedy” for all disputes arising out of or related to the warranty or issues with the home and property. When read together with the warranty’s disclaimer that precluded claims not covered by the warranty “whether in contract, tort, or otherwise,” the statutory building code violation claim could not be remedied through arbitration because it fell outside the warranty’s coverage. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

WINONA COUNTY MINNESOTA ROOFING EXPERT WITNESS DIRECTORY AND CAPABILITIES